Steelcase Workstations and Office Furniture.

SCOPE OF WORKOFFICE FURNITURE FOR THE U.S. ARMY CORPS OF ENGINEERHUNTINGTON DISTRICT, HUNTINGTON, WV Contractor will be responsible for providing all supplies, material, labor and supervision required to deliver and assemble furniture to the U.S. Army Corps of Engineers Huntington District Office, Rooms No. 512 and No. 514 Huntington, WV in accordance with the attached Price Breakout Schedule.If a site visit is needed, please contact Michelle Sabotchick at (304)399-6913.  Ms. Sabotchick will also be the contact for coordinating these services after award. Delivery Information:US Army Corps of EngineersHuntington DistrictAttn:  Michelle Sabotchick502 Eighth St.Huntington, WV 25701Invoices shall be sent to:US Army Corps of EngineersHuntington DistrictAttn:  Michelle Sabotchick502 Eighth St.Huntington, WV 25701  SECURITY REQUIREMENTS A. General: All Contractors and subcontractor employee(s) working on any contract who require access in and/or around any Huntington District facilities,

projects, owned or leased facility/space shall receive authorization to be on site at these areas based upon a favorable background investigation in accordance with “Homeland Security Presidential Directive 12: Policy for a Common Identification Standard for Federal Employees and Contractors” (HSPD 12).  The Huntington District Security Management Office shall submit contractor(s) personal information to complete the basic background investigation in order to make a recommendation to the Contracting Office of an employee’s suitability for work on Government property.   The Procuring Contracting Officer (PCO) has the right to deny any contractor or subcontractor employee from working on any contract based upon the results of the background investigation provided by the Huntington District Security Management Office.  The Government, Contractor, and subcontractors shall not permit any employee(s) access to drawings, blueprints, records, photos, sites, or projects until the Huntington District Security Management Office has completed an Operations Security (OPSEC) review of such items and determined they can be released. B. Pre-bid Meeting: Any Contractor or sub-contractor who plans to attend a pre-bid site visit to any Huntington District facilities, projects, owned or leased facility/spaces must be vetted by having a background investigation conducted by the Security Management Office prior to the site visit. Information for the background investigation must contain the following: a full legal name, complete SSN#, Date of Birth, Place of Birth (City and State).  It is the Contractor’s responsibility to ensure the above information is accurate and legible, otherwise delays may occur.C. Foreign Nationals: The Contractor shall provide the package listed above, as well as additional materials noted below for all Foreign Nationals.  The Contractor is to expect additional time in the approval process for all Foreign Nationals due to the level of review and elevation of the review to Headquarters staff to complete. All Foreign Nationals must be cleared 30 to 45 days in advance of any site visit, tour or work on USACE owned/leased property.  All Foreign Nationals must comply with the following paragraph: In accordance with Engineering Regulation 380-1-18, “Technology Transfer, Disclosure of Information and Contacts with Foreign Representatives” dated 1 August 1996, Section 4, all foreign nationals who work on Corps of Engineers’ contracts shall be approved by the Headquarters US Army Corps of Engineers (HQ USACE) Foreign Disclosure Officer before beginning work on this contract; this regulation includes subcontractor employees.  The Contractor shall submit to the Security Management Office, the names of all foreign nationals proposed for performance under this contract, along with documentation to verify legal admittance into the United States.  Such documentation shall include at least one of the following: a U.S. passport, Certificate of U.S. Citizenship (INS Form N-560 or N-561), Certificate of Naturalization (INS Form N-550 or N-570), Alien Registration Card with photograph (INS Form I-151 or I-551), Employment Authorization Card (INS Form I-688A), etc.    In order to assure forms are properly completed, and to minimize time delays, the Contractor is encouraged to work closely with the Huntington District Security Management Office.  The Government will return for correction incomplete forms, illegible forms, etc. which will delay the contractor / subcontractor from beginning work.  A scanned copy of a valid passport must be sent to the Security Management Office in order to formally request a visit to any Huntington District facilities, projects, owned or leased facility/spaces.Security requirements are subject to change in accordance with HSPD-12, Office of Personnel Management, Engineering or Army regulation or policy changes, etc.  The Government shall add any changes to security requirements by modification to the contract.The Contractor shall contact the Huntington District Security Management Office by phone, letter, or email at the following numbers/addresses: CELRH-SM502 Eighth StreetHuntington, WV  25701 Scott E. Grandon, phone (304) 399-5661; email scott.e.grandon@usace.army.milStephen R. Curry, phone (304) 399-5695; email stephen.r.curry@usace.army.milMatthew D. Green, phone (304) 399-5294; email matthew.d.green@usace.army.milSandra L. Hardwick, phone (304) 399-5612; email sandra.l.hardwick@usace.army.mil                 AT/OPSEC REQUIREMENTS  Access and General Protection/Security Policy and Procedures.All contractor and all associated sub-contractors employees shall comply with applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided bygovernment representative). The contractor shall also provide all information required for background checks to meet installation/facility access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9, Personal Identity Verification of Contractor Personnel) as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any installation or facility change, the Government may require changes in contractor security matters or processes.For contractors who do not require CAC, but require access to a DoD facility or installation.Contractor and all associated sub-contractors employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (Army Directive 2014-05 / AR 190-13), applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative, as NCIC and TSDB are available), or, at OCONUS locations, in accordance with status of forces agreements and other theater regulations.For Contracts that Require OPSEC Training.All new contractor employees will complete Level I OPSEC Training within 30 calendar days of their reporting for duty. Additionally, all contractor employees must complete annual OPSEC awareness training. The contractor shall submit certificates of completion for each affected contractor and subcontractor employee, to the COR or to the contracting officer (if a COR is not assigned), within 5 calendar days after completion of training. OPSEC awareness training is available at the following websites: https://www.iad.gov/ioss/ or http://www.cdse.edu/catalog/operations-security.html; or it can be provided by the RA OPSEC Officer in presentation form which will be documented via memorandum.Pre-screen candidates using E-Verify Program.The Contractor must pre-screen Candidates using the E-verify Program (http://www.uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award. *When contracts are with individuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, with the designated Government representative. This Form will be provided to the Contracting Officer and shall become part of the official contract file.