Installation for Two Entry Ways

BID No. (23005) Installation for Two Entry WaysSealed Bids will be received by the City of Gainesville, Dept of Water Resources, 757 Queen City Parkway, SW Gainesville, GA. 30501 until (2:00 PM)., 10/5/22), for the Installation of Two Entry Ways at Riverside WTP.OVERVIEWThe City of Gainesville, Georgia (Hereafter also referred to as “The City”) seeks Bids to provide Gate Relocation and Fencing for its (Dept of Water Resources Department).The City desires to purchase labor for Installation for two entry ways. Entry Ways are expected to be completed for the (Dept of Water Resources Department) not later than December 30, 2022) BID CORRESPONDENTUpon Release of this Bid, all vendor communications concerning this acquisition must be directed to the Administrative Services Department correspondent listed below:Amy Smith, City of Gainesville’ Dept of Water Resources, 757 Queen City Pkwy, SW Phone: (770.297.2982) FAX: (770.531.2672) ( document.write('asmith'+'@'+'gainesvillega.gov')

rel="no-follow" href="mailto:asmith@gainesvillega.gov">asmith@gainesvillega.gov For security reasons, you must enable JavaScript to view this E-mail address.)James Jones will act a project manager on this project. For site visits and addresses, please contact James Jones at 678-725-2227, 2120 Riverside Dr., Gainesville, GA 30501 or document.write('jjones'+'@'+'gainesvillega.gov')jjones@gainesvillega.gov For security reasons, you must enable JavaScript to view this E-mail address.Unauthorized contact regarding the Bid with other Gainesville City employees may result in disqualification. Any oral communications will be considered unofficial and non-binding on the City of Gainesville. Vendor should rely only on written statements issued by the Bid correspondent.BID QUESTIONSAll questions must be submitted in writing to the Bid correspondents named above. Questions must be received by 10:00 a.m., (09/28/22). A list of questions and answers will be provided to all know Proposers and by Invitation. Invitations may be made to the Bid correspondent named above. BID RESPONSE DATE AND LOCATIONThe Administrative Services department must receive the vendors’ Bid in a sealed envelope, in its entirety, not later than (2:00 pm), Eastern Standard Time in Gainesville, Georgia on 10/5/22. Bids arriving after the deadline will be returned unopened to their senders. All Bids and accompanying documentation will become the property of the City of Gainesville and may not be returned. One (1) original and (1) copy of this Bid must be submitted to allow for evaluation. Bids must be clearly marked on the outside of the package:(Installation for Two Entry Ways - #23005)Vendors assume the risk of the method of dispatch chosen. The City of Gainesville assumes no responsibility for delays caused by any delivery service. Postmarking by the due date will not substitute for actual Bid receipt. Late Bids will not be accepted nor will additional time be granted to any vendor. Bids may not be delivered by facsimile transmission or other telecommunication or solely by electronic means.Bid Schedule: Bid Release: 9/20/22 Bid Questions Deadline: 9/28/22 10:00am Bid Due Date: 10/5/22, 2:00pm Anticipated Award Date: 10/5/22 (subject to final Bid review)WAIVER OF TECHNICALITIESAll items must meet or exceed specifications as stated by the City of Gainesville. The City of Gainesville reserves the right to waive any technicalities and to reject or accept any Bid in its entirety or to accept any portion thereof if it is determined that either method results in lower costs, better service, final satisfaction or is otherwise determined to be in the best interest of the City of Gainesville. Award may be made by item number or in total. Determination of best response to Bid will be the sole judgment of the City of Gainesville. Bids shall remain valid for ninety days for the date of Bid opening.BID REJECTION The City of Gainesville reserves the right to reject any or all Bids at any time without penalty.