Miscellaneous Traffic Signal Construction

Project Title Miscellaneous Traffic Signal Construction Invitation # 6131 Bid Posting Date 01/18/2023 11:40 AM (EST) Project Stage Bidding Bid Due Date 02/14/2023 2:00 PM (EST) Response Format Electronic Project Type Bid Response Types Line Items Subcontractor Bid Bond Type of Award Lump Sum Categories 237310 - Highway, Street, and Bridge Construction 238210 - Electrical Contractors and Other Wiring Installation Contractors License Requirements Department Procurement Services Unit Address 550 Main Street Hartford, Connecticut 06103 County Hartford Bid Valid Liquidated Damages Estimated Bid Value Start/Delivery Date Project Duration Bid Bond Bid Bond 10.00% Payment Bond 100.00% Performance Bond 100.00% Pre-Bid Meeting Information Pre-Bid Meeting No Online Q&A Online Q&A Yes Q&A Deadline 02/09/2023 2:00 PM (EST) Contact Information Contact Info Susan Sheppard 860-757-9616 smsheppard@hartford.gov Bids to Owner's Agent

Description Scope of Services The City of Hartford seeks to retain the services of a qualified contractor experienced in the area of traffic signal construction and repair services. The selected company shall have demonstrated in their submission skills and experience in the electrical and physical construction items for traffic signal construction and the availability of personnel licensed in electrical trades with specific experience in Traffic Signal construction. Other Details Any task priced at $50,000.00 or more will require Performance & Payment Bonds in the amount of 100% of the dollar value of the task. Bonds are not required with bid submission. Where bonding is required, 15% MWBE requirements must be met for each task, subcontracts to be submitted prior to commencement of the work. MWBEs are not required with bid submission. Notes Section 1: Response Forms must be submitted with your bid. Items listed in line items ending with an "A" have been modified per the "Specification Modifications". Special Notices Local Programs & Policies No Contract or Purchase Order, regardless of how procured, shall be awarded to any Person or Candidate that is not an equal opportunity employer. The successful respondent, as a condition of being awarded this contract shall agree to comply with all contractual Equal Employment Opportunity /Affirmative Action performance requirements as outlined herein. A certificate of insurance must be presented to the City in order for the Contract to take effect. The certificate must name the City as an additional insured on the face of the document and must bear the original signature of an authorized Agent for the Producer. All policies must be written on a "per occurrence" basis. The Provider is responsible for the cost of maintaining such insurance throughout the duration of the project. Insurance requirements are detailed in document #1008, Miscellaneous Services Insurance Requirements. The successful respondent will owe no taxes nor have any outstanding financial obligations due the City. Place eBid