Metropolitan Headquarters Courtyard Improvements

Project Title Metropolitan Headquarters Courtyard Improvements Invitation # M-3064 Bid Posting Date 07/28/2023 2:40 PM (PDT) Project Stage Bidding Bid Due Date 09/07/2023 2:00 PM (PDT) Response Format Electronic Project Type Bid Response Types Line Items Subcontractor Bid Bond 00300M, Proposal and Contract (required) 00410, Bidders Bond 00420M, Bidders General Information (required) 00430M, Subcontractor List (required) 00480, Declaration of Non-Collusion (required) Type of Award Lump Sum Categories 77064 - ROOFING, CONCRETE TILE 48525 - CLEANER, TILE AND GROUT 01009 - ACOUSTICAL TILE INSULATION 54542 - MASONRY SAWS AND BLADES (SEE CLASS 755 FOR ROAD AN 91200 - CONSTRUCTION SERVICES, GENERAL 31530 - COATINGS, PROTECTIVE (FOR MASONRY INCLUDING CONCRE 91455 - Masonry 63009 - COATINGS, MASONRY (FOR BRICK, CINDER BLOCK, CONCRE 63022 - FILLERS AND SEALERS MASONRY: BLOCK FILLERS, WATER 13581 - Tile Metal License Requirements classification A, C-54 or C-29 Department Engineering Construction

Address 700 North Alameda Street Los Angeles, California 90703 County Los Angeles Bid Valid 90 Days Liquidated Damages See Specifications Estimated Bid Value $150,000 and $175,000. Start/Delivery Date TBD Project Duration 120 Working Days Bid Bond Bid Bond 10.00% Payment Bond 100.00% Performance Bond 100.00% Pre-Bid Meeting Information Pre-Bid Meeting Yes - Mandatory Pre-Bid Meeting Date 08/10/2023 10:00 AM (PDT) Pre-Bid Meeting Location Metropolitan Headquarters Building, 700 North Alameda Street, Los Angeles, CA 90012 Online Q&A Online Q&A Yes Q&A Deadline 08/17/2023 2:00 PM (PDT) Contact Information Contact Info SpecsDesk SpecsDesk@mwdh2o.com Bids to Metropolitan Water District Owner's Agent N/A Description Scope of Services The work consists of replacing the existing grout and caulking in between the slate and concrete pavers of the courtyard and walkway bollards, replacing damaged decorative stone within the project area and on the walkway bollards; replacing damaged grout as identified on the courtyard fountain, low pressure and temperature power wash of all work area, and other appurtenant work as specified and shown on the drawings. Other Details Prospective bidders must bring a hard copy of the Covid-19 self health review/safety requirements form to the pre-bid meeting. Notes For any login or download related questions, please call PlanetBids Customer Support at 818-992-1771, extension 0 or press red question mark. Special Notices Bid Bond Required Liquidated Damages Apply Payment Bond Required PRE-BID MEETING MANDATORY Prevailing Wage Required Performance Bond Local Programs & Policies Small Business Enterprise and Disabled Veteran Business Enterprise (SBE/DVBE) participation of 25% Place eBid